Acceptance of Service Terms

By accessing and using MeasureCraft Kitchens JP services, you accept and agree to be bound by the terms and provision of this agreement.

If you do not agree to abide by the above, please do not use this service. These terms apply to all visitors, users, and others who access or use the service.

Service Description and Scope

MeasureCraft Kitchens JP provides custom kitchen design, measurement, planning, and project management services for residential properties in .

Our services include 3D measurement, kitchen planning, cabinetry design, appliance integration, and coordination with local contractors for installation.

User Account Responsibilities

You are responsible for maintaining the confidentiality of your account information and for all activities that occur under your account.

You agree to notify us immediately of any unauthorized use of your account or any other breach of security.

Project Consultation and Planning

Initial consultations are provided free of charge and do not constitute a binding agreement for services.

Detailed project planning and design services require a signed agreement and may involve fees as outlined in your project proposal.

Measurement and Design Accuracy

While we strive for precision in all measurements and designs, you acknowledge that minor variations may occur during fabrication and installation.

We guarantee our measurements within industry-standard tolerances and will address any significant discrepancies at no additional cost.

Payment Terms and Conditions

Payment schedules and terms will be specified in your individual project agreement. Generally, payments are required at key project milestones.

Late payments may result in project delays and additional fees. All prices are subject to applicable taxes and fees.

Contractor Network and Installation

We work with a network of vetted local contractors for fabrication and installation services. While we manage these relationships, the contractors are independent entities.

We coordinate installation schedules and quality control but are not directly responsible for contractor performance beyond our management role.

Product Warranties and Guarantees

We provide warranties on our design services and coordinate manufacturer warranties on products and materials.

Warranty terms vary by product and service type and will be detailed in your project agreement and product documentation.

Project Timeline and Delays

Project timelines are estimates based on typical conditions. Actual completion may vary due to factors beyond our control.

We will communicate any significant delays promptly and work to minimize impact on your project schedule.

Limitation of Liability

Our liability is limited to the value of services provided. We are not liable for indirect, incidental, or consequential damages.

This limitation applies to all claims, whether based on warranty, contract, tort, or any other legal theory.

Intellectual Property Rights

All designs, plans, and creative work produced by MeasureCraft Kitchens JP remain our intellectual property until full payment is received.

Upon full payment, you receive a license to use the designs for your specific project but may not reproduce or distribute them.

Cancellation and Refund Policy

Project cancellations must be made in writing. Refund eligibility depends on the project stage and work completed.

Detailed cancellation terms will be specified in your individual project agreement.

Dispute Resolution Process

Any disputes arising from these terms or our services will first be addressed through good faith negotiation.

If negotiation fails, disputes will be resolved through binding arbitration in accordance with Japanese law.

Governing Law and Jurisdiction

395-1 Kitafukusaki, Kawagoe Town, Mie District, Mie Prefecture, 510-8125

If any provision of these terms is found to be unenforceable, the remaining provisions will continue in full force and effect.

Terms Modification and Updates

We reserve the right to modify these terms at any time. Changes will be posted on this page with an updated effective date.

Your continued use of our services after any changes constitutes acceptance of the new terms.

Contact Information for Legal Matters

For questions about these terms or legal matters, please contact us at:

Email: legal@peonywaveflorist.com
Phone: +81 70-4938-2716
Address: 395-1 Kitafukusaki, Kawagoe Town, Mie District, Mie Prefecture, 510-8125